Appellate

Overview

A generation ago, it was accepted wisdom that the lawyer who tried a case should be the one to prosecute or defend any appeal arising from the judgment. Robinson+Cole, in the vanguard of law firms in this area, recognized that the successful handling of an appeal calls for a different skill set than that wielded by the average trial lawyer. 

For more than 40 years, the Robinson+Cole roster has included specially trained lawyers in the art of appellate advocacy who are not only fluent in the appellate rules but also highly skilled in the critical tasks of issue identification, issue preservation, strategic positioning, and persuasive argument. Our lawyers understand how to best craft and present legal issues to appellate jurists—and have spent decades sharpening their talents.

Members of our group have been involved in successful appeals in the U.S. Supreme Court as well as the highest courts in Connecticut, New York, Massachusetts, Rhode Island, and Virginia. Robinson+Cole’s Appellate Group was named Connecticut's premiere appellate group by the Connecticut Law Tribune in 2014.

Our Services

The lawyers in Robinson+Cole’s Appellate Group, most of whom are former appellate law clerks, regularly handle appeals in both the state and federal courts. In addition to the group’s long history of successes in the Connecticut appellate courts, our appellate lawyers have handled multiple appeals in New York, New Jersey, and throughout New England, as well as in other state courts (including Arizona, Florida, Louisiana, and Mississippi) and in 12 of the 13 federal circuit courts of appeal.

The appellate know-how of our group frequently takes us to other fora, where our skills in persuasive briefing and strong oral advocacy are equally applicable in different closed-record proceedings, such as administrative agency appeals (both state and federal), arbitration appeals, ERISA appeals, and bankruptcy appeals.

Collaboration

Working on a team comes easily to Appellate Group members, who are often asked to collaborate before an appeal is docketed, sometimes before an appeal is even contemplated. Our lawyers routinely become involved in a case months or years before a judgment has been entered. An appellate lawyer’s background and know-how can be indispensable in pretrial motion practice and as a trial progresses, especially when it comes to strategic planning and issue preservation. As part of a litigation team, an appellate lawyer can assist trial counsel in identifying (and often correcting) potential problems before the trial concludes. Moreover, an appellate lawyer can provide an invaluable skill set by helping draft dispositive motions, pre- and post-trial briefs, jury instructions, and post judgment motions. 

These same skills are also useful in cases where an appellate lawyer is needed to collaborate on—rather than fully manage—a newly filed appeal. Every appeal is different; sometimes it is best to keep the participation of an appellate attorney discreet. The members of our Appellate Group are adept team players and continually strive to find the ideal way to achieve the best result in every given situation.

Amicus Curiae

Amicus curiae (friend-of-the-court) briefs are filed by a person or group who has a strong interest in the outcome of the subject matter of a pending lawsuit even though not themselves a party. Amicus briefs serve multiple purposes, including to address policy issues, provide a sympathetic viewpoint, supplement/bolster a party's brief, or provide historical perspective or technical assistance. Members of Robinson+Cole's Appellate Group regularly represent amici curiae on issues of first impression or that may have broad application in significant industry areas. The input of industry leaders on such issues cannot be overstated; judges who decide these important issues often actively seek guidance from those who intimately know the specific area. Our group’s members understand how to objectively, persuasively, and succinctly present critical information to the courts.

Our Team

The Appellate Group has six core members, each with substantial appellate experience: 

Linda L. Morkan, the Group’s chair, is the first Connecticut woman inducted into the American Academy of Appellate Lawyers and has been involved in more than 200 appeals, including in the United States Supreme Court. Ms. Morkan has been named as one of The Best Lawyers in America© in the area of Appellate Law since 2008 and has been included in the Top 25 Connecticut Women Super Lawyers since 2006.

Wystan M. Ackerman has a national appellate practice focusing on insurance coverage and class actions, regularly representing insurers and national insurance industry associations (as amicus curiae) on critical insurance coverage issues. He has been involved in more than 40 insurance-related appeals, including recently successfully arguing the first Hurricane Sandy-related insurance coverage case heard by the New Jersey Supreme Court and a case in the First Circuit establishing the law on critical issues of liability insurance coverage. Mr. Ackerman was successful in persuading the United States Supreme Court to accept certiorari in Standard Fire Ins. v. Knowles, 133 S. Ct. 1345 (2013), which resulted in a reversal in favor of our client’s interpretation of the Class Action Fairness Act.

Bradford S. Babbitt, co-chair of the firm's Litigation Group and a former appellate law clerk, has handled appeals in New York and in Connecticut, with a particular emphasis on administrative appeals from regulatory rulings and other utility-related litigation. His experience in this area includes the Connecticut Supreme Court case that established the preemptive power of the Connecticut Siting Council over municipal zoning authorities.

Thomas J. Donlon is a former senior appellate counsel for the United States Coast Guard. While at Robinson+Cole, Mr. Donlon has handled over 30 appeals, not only in the Connecticut and New York state courts but also in the Second, Third, Ninth, and Federal Circuit Courts of Appeals. Among his many victories, Mr. Donlon won an appeal upholding the largest condemnation award, for over $125 million plus interest, against the State of New York. 

Stephen E. Goldman, the firm’s managing partner, has served as counsel for insurers in many significant property insurance and class action cases, including Standard Fire v. Knowles, 133 S. Ct. 1345 (2013) (holding that the plaintiff's stipulation cannot defeat federal jurisdiction under the Class Action Fairness Act) and Travco v. Ward, 736 S.E.2d 321 (Va. 2012) (affirming the trial court's judgment that property insurance policies do not cover losses caused by the presence of Chinese drywall). 

Jeffrey J. White, a former clerk to Connecticut Supreme Court Chief Justice Ellen Ash Peters, has been involved in over 50 appeals, including a successful argument before the Connecticut Supreme Court in an antitrust case arising out of a proposed $1 billion waterfront project. Mr. White has argued before the United States Court of Appeals for the Second Circuit and the state appellate courts in Connecticut, New York. and Maryland. 

In addition, the Robinson+Cole Appellate Group includes several supporting lawyers, including many recent appellate law clerks.

 
    • Experience
      • Bankruptcy

      • Secured reversal and remand of Bankruptcy Court’s refusal to allow a plaintiff to open the debtors’ Chapter 11 cases and modify the discharge injunction. HDR Architecture P.C. v. Maguire Group Holdings, 523 B.R. 879 (2014), appeal withdrawn, docket no. 15-10324 (11th Cir. 2015). 

      • Business Disputes/Arbitration

      • Obtained reversal of a trial court’s refusal to enforce terms of several promissory notes and award of damages to defaulting defendant and succeeded on issue of first impression regarding who has standing to raise an Unfair Trade Practices Act claim against a lender. Channing Real Estate v. Gates, 326 Conn. 123 (2017).

      • Represented a Connecticut employer concerning the extent to which the Connecticut Constitution's Declaration of Rights protects employees' free speech rights in the workplace. Trusz v. UBS Realty investors, 319 Conn. 175 (2015).

      • Successfully defended defense verdict in a multimillion-dollar lease termination case. DiNardo Seaside Tower v. Sikorsky Aircraft, 153 Conn. App. 10, cert. denied, 314 Conn. 947 (2014).

      • Reversed trial court judgment in favor of a defendant where court improperly relied on the doctrine of frustration of purpose. DDS Wireless International Inc. v. Nutmeg Leasing, Inc., 145 Conn. App. 520 (2013).

      • Successfully defended a trial court’s foreclosure judgment in favor of a lender against the claims of a church. Silicon Valley Bank v. Miracle Faith World Outreach, Inc., 140 Conn. App. 827, cert. denied, 308 Conn. 930 ( 2013).

      • Secured affirmance of summary judgment for an employer in a wrongful termination dispute. Callender v. Reflexite, 143 Conn. App. 351, cert. denied, 310 Conn. 905 (2013).

      • Summary judgment affirmed for a defendant employee on a claim under the Computer Fraud and Abuse Act (CFAA), 18 U.S.C.S. § 1030, as the employer failed to present sufficient, specific evidence regarding what data, if any, fell outside the scope of the defendant’s authorized access at the time he downloaded it. Amphenol v. Paul, 591 Fed. Appx. 34 (2015).

      • Dismissal of plaintiff's motion to confirm an arbitration award was reversed as defendants' motion to dismiss was improperly treated as if it implicated the trial court's subject matter jurisdiction. Directory Assistants Inc. v. Big Country Vein, L.P., 134 Conn. App. 418 (2012).

      • Defended a parish and diocese of the Episcopal Church against claims asserted by a former parishioner that he was abused by a member of the clergy in 1977. Successfully obtained dismissal of claims based in vicarious liability. Later won summary judgment on claims sounding in negligent hiring, supervision, retention, and breach of fiduciary duty based on the absence of knowledge of a propensity to abuse by the leadership of the parish and the diocese before the time of the abuse. Successfully defended that judgment at the Connecticut Appellate Court. Gough v. St. Peter’s Episcopal Church, 143 Conn. App. 719 (2013).

      • Successfully represented a group of national and international insurance companies in appeal proceedings that stemmed from the issuance of a multimillion-dollar arbitration award that arose out of an insurance loss that occurred at a coal-fired electrical generating facility. The appellate process was conducted in two different phases and was litigated in both the Connecticut Appellate and Supreme Courts and at the U.S. Supreme Court. Ultimately, the Connecticut Appellate Court affirmed the trial court's granting of a motion to confirm the arbitration award in our clients' favor. Furthermore, the Appellate Court affirmed the awarding of pre and postjudgment interest, which resulted in the payment of a judgment of over $6.5 million. Hartford Steam Boiler v. Underwriter's at Lloyds, 121 Conn. App. 31 (2010), cert. denied, 297 Conn. 918 (2010).

      • Construction

      • Obtained reinstatement of multimillion-dollar liquidated damages award in favor of a contractor against the Connecticut Department of Transportation. White Oak Corp. v. DOT, 319 Conn. 582 (2015).

      • Defended trial court's holding that, in light of the express terms of the parties' contract, the Town of Southington's election to terminate the contract for convenience did not preclude it from recovering liquidated damages against the contractor because that right arose as soon as the substantial completion date passed and continued to accrue until the termination of the contract. Old Colony Constr. LLC v. Town of Southington, 316 Conn. 202 (2015).

      • Eminent Domain

      • Won decision in an eminent domain proceeding versus the State of New York upholding the largest condemnation award in New York history, totaling $125 million. Robinson+Cole also represented the client, a real estate investment trust in the New York City metropolitan area, in an appeal before the Appellate Division of the Supreme Court, Second Department, of the State of New York, which issued a unanimous decision and order in affirming the judgment of the Court of Claims in June 2010. The Appellate Division ordered the state to pay the original award plus interest, bringing the total award to approximately $160 million. Gyrodyne Company of America v. State of New York, 89 A.D.3d 988 (2011).

      • Successfully represented owners of a 77-acre parcel in an appeal to the Connecticut Supreme Court that arose out of the condemnation of that parcel by a municipality. The taking spawned two proceedings: In the first, the property owners challenged the municipality's valuation of the property. In the second, the jury found that the municipality had taken the property in bad faith in violation of the Fifth Amendment and awarded the property owners additional monies that represented the loss of an option contract. On appeal, the Supreme Court affirmed the finding that the property was worth $4.6 million as well as the jury's verdict that the municipality acted in bad faith by taking the property. The Court also upheld our clients' cross-appeal, agreeing that they should have been awarded all of their attorneys’ fees. Branford v. Santa Barbara, 294 Conn. 785 (2010); Branford v. Santa Barbara, 294 Conn. 803 (2010); New England Estates, LLC v. Branford, 294 Conn. 817 (2010).

      • Land Use

      • In a series of cases of first impression under the state wetlands statute, defined the limited scope of statutory exceptions, established the authority of courts to protect and restore wetlands with injunctions, as well as the right of private parties to recover attorneys fees. Red 11 LLC v. Conservation Commission, 117 Conn. App. 630, cert. denied, 294 Conn. 918 (2009); Conservation Commission v. Red 11 LLC, 119 Conn. App. 377, cert. denied, 295 Conn. 924 (2010);  Conservation Commission v. Red 11 LLC, 135 Conn. App. (2012).

      • Obtained reversal of summary judgment against landowners to declare certain restrictive covenants null and void because, contrary to the trial court's conclusions, the covenants at issue were not void as a matter of law, and questions of material fact existed as to whether the defendants were entitled to enforce them. Wykeham Rise v. Federer, 305 Conn. 448 (2012).

      • Representation of the owner of a rare, undeveloped peninsular building lot on Long Island Sound in an administrative appeal from the town's denial of a zoning permit. Persuaded the trial court to reverse the town's denial and to order the town to grant all permits necessary to construct our client's home on the property. Successfully defeated a petition for certification to the Connecticut Appellate Court. Kleinknecht v. Stonington ZBA, 2010 Conn. Super. LEXIS 3347 (Dec. 16, 2010) (denial of petition for certification not published).

      • Recognizing for the first time a private right of action under the state wetlands statute. Windels v. Environmental Protection Comm’n, 284 Conn. 268 (2007).

      • Health Care/Life/ERISA

      • Second Circuit affirmed dismissal of plaintiff’s ERISA claim that the defendants failed to timely provide her copies of plan documents. Brown v. Rawlings Financial Servs. LLC, 868 F.2d 126 (2017).

      • Secured affirmance of grant of summary judgment on the question of whether designee of the state Department of Social Services could compel reimbursement of medical costs from Medicaid recipients after recovery from a liable third party. Rathbun v. Health Net, 315 Conn. 674 (2015).

      • The Second Circuit affirmed grant of summary judgment to a life and disability insurer where the policy unambiguously limited residual disability benefits. Frank v. Reassure Life Ins. Co., 548 Fed. Appx. 706 (2013).

      • Affirming trial court’s ruling that the defendant insurer did not violate the prohibition against "unfair discrimination" in Conn. Gen. Stat. § 38a-816(10) in paying reimbursement to practitioners of the healing arts by paying podiatrists less than medical doctors for the same services. Connecticut Podiatric Medical Assn v. Health Net, 302 Conn. 464 (2011).

      • Insurance Appeals

      • For more information on Robinson+Cole's Insurance Appeals group description, click here

      • Probate

      • Successfully defended trustees against a claim by a future trust beneficiary that they were misapplying the terms of the multimillion-dollar trust and distributing income incorrectly. Heisinger v. Dillon, 168 Conn. App. 467, cert. denied, 323 Conn. 940 (2016); companion case: In re Probate Appeal of Heisinger, 168 Conn. App. 467, cert. denied, 323 Conn. 941 (2016).

      • Utilities

      • Defeated attempts by antinuclear activists to prevent the installation of a dry storage system for spent nuclear fuel. Representation included multiple evidentiary hearings on a motion for stay, pending an administrative appeal; evidentiary hearings regarding alleged bias by members of the reviewing administrative agency; and a motion to dismiss on federal preemption grounds. Prevailed on each issue at every level. The Connecticut Supreme Court adopted our analysis of the preemption issue in a case of first impression in the state. Connecticut Coalition Against Millstone v. Connecticut Siting Council, 286 Conn. 57 (2008).

      • Persuaded trial court to dismiss appeal for lack of standing where appellant challenged the Connecticut Siting Council authorization to build and operate a telecommunications facility in northwest Connecticut; successfully defended that decision and numerous other issues raised on appeal at the Connecticut Appellate Court and the Connecticut Supreme Court.

      • Appellate

      • Obtained favorable judgments on appeal at the United States Courts of Appeal for the Second and Federal Circuits in several patent and trademark infringement cases. 

      • Obtained reversal at the Connecticut Supreme Court for a $4.5 million jury award for loss-of-consortium entered in a medical malpractice action.

      • Obtained reversal at the Connecticut Supreme Court in a case involving personal jurisdiction over an out-of-state insurer. 

      • Obtained reversal of a felony murder conviction at the Connecticut Supreme Court based on a claim that certain forensic DNA evidence violated the defendant’s constitutional right to confrontation

      • Obtained reversal of a murder conviction at the Connecticut Supreme Court based on a claim that the defendant was deprived of his constitutional right to counsel at trial.

      • Obtained reversal of a “fighting words” conviction at the Connecticut Supreme Court based on a claim that the conviction violated the defendant’s First Amendment right to freedom of speech.

      • back to top
    • News
      • November 1, 2023

        Linda Morkan Completes Term as Leader of the UConn Law School Alumni Association

        • » more info
      • October 26, 2023

        Robinson+Cole Lawyers Recognized in 2023 Super Lawyers®

        • » more info
        • View article
      • October 10, 2023

        Robinson+Cole Recognized in 2024 Edition of Benchmark Litigation

      • August 17, 2023

        78 Robinson+Cole Lawyers Listed in The Best Lawyers in America© 2024

        • » more info
        • View article
      • March 7, 2023

        Linda Morkan and Brian Smith Featured in Connecticut Law Tribune for Successful View Easement Appeal

        • » more info
        • View article
      • February 1, 2023

        Linda Morkan Quoted in Law360 Story on Appellate Practices

        • » more info
      • November 3, 2022

        Robinson+Cole Receives 43 First-Tier Metropolitan Rankings and Four National Rankings in Latest U.S. News – Best Lawyers “Best Law Firms”

        • » more info
        • View article
      • October 26, 2022

        Linda Morkan Elected President of UConn Law Alumni Association Board of Directors

        • » more info
      • October 11, 2022

        Robinson+Cole Lawyers Recognized in 2022 Super Lawyers®

        • » more info
        • View article
      • September 30, 2022

        Robinson+Cole Recognized by Benchmark Litigation

      • November 4, 2021

        Robinson+Cole Receives 40 First-Tier Metropolitan Rankings and Four National Rankings in Latest U.S. News – Best Lawyers “Best Law Firms”

        • » more info
        • View article
      • October 30, 2021

        Linda Morkan Elected President-elect of UConn Law School Alumni Association Board of Directors

        • » more info
      • October 7, 2021

        Robinson+Cole Recognized by Benchmark Litigation

      • August 19, 2021

        65 Robinson+Cole Lawyers Listed in The Best Lawyers in America© 2022

        • » more info
        • View article
      • July 14, 2021

        Andrew DePeau, Tom Donlon and Evan Seeman Present at CBA's 2021 Connecticut Legal Conference

        • » more info
      • June 18, 2021

        Jess Hamilton and Linda Morkan Author Articles Published in ABA TIPS Spring Newsletter

        • » more info
        • View article
      • May 13, 2021

        Connecticut Law Tribune Honors Seven Robinson+Cole Lawyers During Connecticut Legal Awards

        • » more info
        • View article
      • November 6, 2020

        Robinson+Cole Receives 36 First-Tier Metropolitan Rankings and Four National Rankings in Latest U.S. News – Best Lawyers “Best Law Firms”

        • » more info
        • View article
      • October 15, 2020

        47 Robinson+Cole Lawyers Recognized in Super Lawyers®

        • » more info
        • View article
      • October 8, 2020

        Robinson+Cole Recognized in Benchmark Litigation

      • August 20, 2020

        61 Robinson+Cole Lawyers Listed in The Best Lawyers in America© 2021

        • » more info
        • View article
      • November 1, 2019

        Robinson+Cole Receives 33 First-Tier Metropolitan Rankings and Four National Rankings in Latest U.S. News – Best Lawyers “Best Law Firms”

        • » more info
        • View article
      • October 2, 2019

        Robinson+Cole Recognized by Benchmark Litigation

      • August 15, 2019

        57 Robinson+Cole Lawyers Listed in The Best Lawyers in America© 2020

        • » more info
        • View article
      • May 23, 2019

        Firm Lawyers Contribute to CBA's Appellate Advocacy Institute

        • » more info
      • January 16, 2019

        Jeff White Appointed to Serve on State of Connecticut Ebriefs Committee

        • » more info
      • December 11, 2018

        Robinson+Cole Hosts CBA Appellate Advocacy Section Meeting Featuring Judge Elgo

        • » more info
      • November 1, 2018

        Robinson+Cole Receives 36 First-Tier Metropolitan Rankings and Four National Rankings in Latest U.S. News – “Best Law Firms” Survey

        • » more info
        • View article
      • October 24, 2018

        Robinson+Cole Recognized by Benchmark Litigation

      • October 18, 2018

        51 Robinson+Cole Lawyers Recognized by Super Lawyers®

        • » more info
        • View article
      • July 18, 2018

        Tom Donlon Contributes to ABA Section of Litigation Publication

        • » more info
      • December 11, 2017

        Robinson+Cole Elects New Partners

      • November 1, 2017

        Robinson+Cole Receives 37 First-Tier Metropolitan Rankings and 3 National Rankings in Latest U.S. News – Best Law Firms Survey

        • » more info
        • View article
      • October 17, 2017

        Robinson+Cole Lawyers Recognized by Super Lawyers®

        • » more info
        • View article
      • September 21, 2017

        Tom Donlon's Latest Column Published in ABA Journal

        • » more info
      • August 15, 2017

        Fifty-Nine Robinson+Cole Lawyers Listed in The Best Lawyers in America© 2018

        • » more info
        • View article
      • March 31, 2017

        Tom Donlon Publishes Two Articles for ABA Journal

        • » more info
      • November 2, 2016

        Tom Donlon's ABA Column Is Among the Most Read

        • » more info
      • November 1, 2016

        Robinson+Cole Receives 34 First-Tier Metropolitan Rankings and 3 National Rankings in Latest U.S. News – Best Law Firms Survey

        • » more info
        • View article
      • October 18, 2016

        Robinson+Cole Lawyers Recognized by Super Lawyers®

        • » more info
        • View article
      • August 15, 2016

        Robinson+Cole Receives Top Listing in Connecticut Lawyer Count in The Best Lawyers in America® 2017

        • » more info
        • View article
      • March 15, 2016

        Tom Donlon's Column Reprinted in ABA's Litigation News

        • » more info
      • January 11, 2016

        Tom Donlon Column Appears in ABA Appellate Practice Journal

        • » more info
      • November 3, 2015

        Robinson+Cole Recognized in Benchmark Litigation 2016

        • » more info
        • View article
      • September 4, 2015

        Kathleen E. Dion Lawyer Elected to KNOX Board of Directors

        • » more info
        • View article
      • August 25, 2015

        Tom Donlon Begins New Column in ABA Appellate Practice Journal

        • » more info
      • August 18, 2015

        Robinson+Cole Receives Top Listing in Connecticut Lawyer Count in The Best Lawyers in America® 2016

        • » more info
        • View article
      • April 23, 2015

        Robinson+Cole Successfully Defends Connecticut Municipality in Construction Contract Case

        • » more info
      • March 23, 2015

        Tom Donlon Publishes Article on Trial Strategies for Winning Appeals

        • » more info
      • October 30, 2014

        Robinson+Cole Recognized by Benchmark Litigation

        • » more info
        • View article
      • October 29, 2014

        Two Robinson+Cole Lawyers Recognized on Super Lawyers Top Lists

        • » more info
      • May 14, 2014

        Robinson+Cole's Appellate Group Wins Connecticut Law Tribune's Litigation Department of the Year Award

        • » more info
      • May 12, 2014

        Tom Donlon Participates in CLE Panel Discussion at National ABA Conference

        • » more info
      • March 4, 2014

        Jeffrey White Appointed Corporator of Saint Francis Hospital and Medical Center Foundation

        • » more info
        • View article
      • February 12, 2014

        Robinson & Cole Welcomes Eight New Lawyers

        • » more info
        • View article
      • November 1, 2013

        Robinson & Cole Receives 34 First-Tier Metropolitan Rankings and Three National Rankings in U.S. News – Best Lawyers Survey

        • » more info
        • View article
      • October 21, 2013

        Super Lawyers® Names 61 Robinson & Cole Attorneys to 2013 List

        • » more info
        • View article
      • September 25, 2013

        Tom Donlon Appointed to New Position with ABA's Section of Litigation

        • » more info
      • August 27, 2013

        Robinson & Cole Lawyers Provide Commentary in Law360

        • » more info
      • August 16, 2013

        Linda Morkan Listed in Benchmark's Top 250 Women in Litigation

        • » more info
      • August 16, 2013

        Robinson & Cole Receives Top Listing in Connecticut Attorney Count in Best Lawyers National Peer Review Survey

        • » more info
        • View article
      • April 19, 2013

        J. Tyler Butts Pens Hurricane Sandy Article for DRI’s For The Defense

        • » more info
      • January 9, 2013

        Jeffrey J. White Receives “40 Under 40: Class of 2013” Award

        • » more info
      • January 7, 2013

        J. Tyler Butts Writes Article on How Young Attorneys Can Prepare for Out-of-State Appeals

        • » more info
      • December 13, 2012

        Robinson & Cole Attorneys Earn Additional Honors for Pro Bono Work

        • » more info
        • View article
      • December 4, 2012

        Linda Morkan Wins Issue of First Impression at Connecticut Supreme Court

        • » more info
      • November 7, 2012

        Robinson & Cole Receives 32 First-Tier Metropolitan Rankings and Four National Rankings in U.S.News - Best Lawyers Survey

        • » more info
        • View article
      • October 31, 2012

        Appellate Attorneys Write Article Analyzing Significant Business Law Cases Decided By Connecticut Supreme Court In 2012

        • » more info
      • October 22, 2012

        ABA Title Insurance Litigation Committee Publishes Article by Robinson & Cole Attorney

        • » more info
      • September 27, 2012

        Appellate Attorneys Author Chapters in The Appellate Practice Compendium

        • » more info
      • August 28, 2012

        Robinson & Cole Receives Top Listing in Connecticut Attorney Count in Best Lawyers National Peer Review Survey

        • » more info
        • View article
      • July 26, 2012

        Robinson & Cole Attorney Linda L. Morkan Named as One of the Top 250 Women Litigators in the United States

        • » more info
        • View article
      • July 23, 2012

        Appellate Attorney's Article Published in American Bar Association Newsletter

        • » more info
      • May 29, 2012

        Linda Morkan Featured Speaker At 2012 Appellate Advocacy Institute

        • » more info
      • December 16, 2011

        Benchmark Litigation 2012 Recognizes Six Robinson & Cole Attorneys

        • » more info
        • View article
      • December 1, 2011

        Unanimous ruling by Appellate Panel in Eminent Domain Case

        • » more info
      • October 19, 2011

        Class Dismissed! Appellate Team Wins Summary Judgment for Health Insurer

        • » more info
      • July 5, 2011

        Linda Morkan Writes Article for Connecticut Law Tribune's Special Section on Alternative Dispute Resolution

        • » more info
      • April 25, 2011

        Attorney's Article Selected to Help Train Judges on Judicial Ethics

        • » more info
      • March 3, 2011

        Robinson & Cole Amicus Brief Analyzes Controversial Loss of Consortium Claim

        • » more info
      • September 27, 2010

        Recent Supreme Court Decisions Impact the Business Community

        • » more info
      • September 2, 2010

        Mock Argument Examines Potential Gender Influence on Decision Making

        • » more info
      • August 19, 2010

        Linda L. Morkan Examines Supreme Court’s Decision in Stolt-Nielsen

        • » more info
      • July 20, 2010

        Thomas J. Donlon Appointed Cochair of the ABA Appellate Committee

        • » more info
      • June 11, 2010

        Robinson & Cole Attorney Writes Second Article Published in Connecticut Lawyer

        • » more info
      • February 24, 2010

        Robinson & Cole Attorney Publishes Article on Judicial Disqualification

        • » more info
      • November 10, 2008

        Robinson & Cole Appellate Attorney Publishes Article in ABA Publication TortSource

        • » more info
      • October 10, 2008

        Robinson & Cole Appellate Attorney Authors Article for Connecticut Law Tribune

        • » more info
      • August 22, 2008

        Robinson & Cole Appellate Chair Authors Article for DRI Publication

        • » more info
      • August 4, 2008

        Robinson & Cole Attorney Recently Re-Appointed as a Vice-Chair of the Appellate Advocacy General Committee

        • » more info
      • May 28, 2008

        Robinson & Cole Attorney Receives ABA Award

        • » more info
    • Publications + Presentations
    • "Zoning Appeals for Real Property Lawyers," co-presented by Evan J. Seeman and Scott T. Garosshen, as part of the Connecticut Bar Association’s (CBA) Real Property Section Meeting (11/16/2023)
      • » more info

      "Appellate Law Considerations in Family Law Cases," presented by Scott T. Garosshen, panelist as part of the Connecticut Bar Association's 2023 Connecticut Legal Conference (6/5/2023)
      • » more info

      "Are We Done Yet? A Primer on When to Appeal," presented by Linda L. Morkan, presented by the Appellate Advocacy Section of the CT Bar Association as part of the 2022 CT Legal Conference (6/13/2022)
      • » more info

      "New E-Briefing Rules for CT's Appellate Courts," presented by Linda L. Morkan, a panel presentation to the Connecticut Bar Association Appellate Advocacy Section (10/6/2021)
      • » more info

      "Obtaining ABA Amicus Support For Your Appeal," published in Appellate Practice Journal, authored by Thomas J. Donlon (Winter 2017)
      • » more info
      • View article

      "Silly Lawyer Tricks," published in Appellate Practice Journal, authored by Thomas J. Donlon, a regular column (Winter 2017)
      • » more info
      • View article

      "Introducing Our Massachusetts Appellate Blog" (5/19/2016)

      "Silly Lawyer Tricks," published in Litigation News, authored by Thomas J. Donlon, a regular column (5/10/2016)
      • » more info
      • View article

      "Silly Lawyer Tricks," published in Appellate Practice Journal, authored by Thomas J. Donlon, a regular column (Winter 2016)
      • » more info
      • View article

      "Silly Lawyer Tricks," published in Appellate Practice Journal, authored by Thomas J. Donlon, a regular column (Fall 2015)
      • » more info
      • View article

      "Connecticut Supreme Court Upholds Jurisdiction of Arbitration Panel for Claims Arising on Public Works Construction" (12/2/2015)

      "Silly Lawyer Tricks," published in ABA Appellate Practice Journal, authored by Thomas J. Donlon, initial column in the journal (Summer 2015)
      • » more info
      • View article

      "Termination for Convenience Contract Provision Retains Responsibility for Liquidated Damages" (4/20/2015)

      "Winning Your Appeal At Trial," published in ABA Appellate Practice Journal, authored by Thomas J. Donlon (Winter 2015)
      • » more info

      "Welcome to the Fall 2014 Issue of Appellate News!" (11/11/14)

      "Welcome to the Summer 2014 Issue of Appellate News!" (7/8/2014)

      "For the Record from Start to Finish," presented by Thomas J. Donlon, panelist for this program presented at the American Bar Association's (ABA) Section of Litigation Annual Conference, Scottsdale, Arizona (4/11/2014)

      "Connecticut Appellate Court Rules Data Breach Losses Not Recoverable Under General Liability Policy" (02/27/2014)

      "Appellate News" (10/17/2013)

      "Arbitration and Sexual Harassment in the Workplace," published in Connecticut Law Tribune, co-authored by Jeffrey J. White and Jamie M. Landry, appeared in the special supplement Connecticut Supreme Court Review 2013. The article reviews several Connecticut Supreme Court decisions in 2012–13 that have an impact on the business community. (9/30/2013)

      "Chevron: Stronger Than Ever in City of Arlington, Texas," published in Appellate Practice Journal, authored by Bradford S. Babbitt, a publication of the American Bar Association (9/30/2013)

      "Appellate News" (05/02/2013)

      "Harsh Words and Broken Leases," co-authored by Jeffrey J. White and Jamie M. Landry, published in Connecticut Law Tribune, appeared in the special supplement Connecticut Supreme Court Review 2012. The article reviews several Connecticut Supreme Court decisions in 2012 that have an impact on the business community. (9/17/2012)

      "Unfamiliar Territory: Preparing for Your First Out-of-State Appeal," published in Appellate Practice, authored by J. Tyler Butts, the newsletter of the American Bar Association's Section of Litigation (Fall 2012)

      "Class Action Fairness Act Interlocutory Appeals," authored by Wystan M. Ackerman, published in In-House Defense Quarterly, a publication of the Defense Research Institute (Fall 2012)

      "Vacating Arbitration Decision Not an Appealing Task," published in Connecticut Law Tribune, authored by Linda L. Morkan (6/20/2011)

      "Some Obvious and Not-So-Obvious Tips: Writing a More Persuasive Brief," published in For the Defense, authored by Jeffrey J. White, a national publication of the Defense Research Institute (12/2010)

      "Celebrating Women on the Appellate Bench: A Mock Argument Examining Potential Gender Influences on Decision Making," at American Bar Association Annual Meeting, presented by Thomas J. Donlon (8/2010)

      "For Corporations, Home Is Where 'Nerve Center' Is: High Court Defines 'Principal Place of Business,' Streamlines Litigation," published in Connecticut Law Tribune, co-authored by Jeffrey J. White and Laura A. Torchio (4/29/2010)

      "Winning Strategies for Appellate Advocacy: The View from the Bench," at American Bar Association's Section of Litigation Annual Conference, presented by Thomas J. Donlon (4/2010)

      "Judical Disqualification: What's Next for Connecticut?" published in Connecticut Lawyer, authored by Thomas J. Donlon (12/2009)

      "Bad News for Disgruntled Minority Shareholders," published in Connecticut Law Tribune, authored by Jeffrey J. White, in the special supplement Connecticut Supreme Court Review 2009. The article reviewed several Connecticut Supreme Court decisions in 2009 that have an impact on the business community. (September 2009)

      "The Future of Caperton v. Massey in State Appellate Courts," published in ABA Appellate Practice Journal, authored by Thomas J. Donlon (Fall 2009)

      "Ten Tips for More Persuasive Writing and an Introduction to the New Requirements for Electronic Brief Submission," at Connecticut Bar Association annual meeting, co-presented by Linda L. Morkan and Hon. Douglas S. Lavine, Connecticut Appellate Court, Professor Susan R. Dailey, and Steven D. Ecker (6/8/09)

      "The Tough Case Is Not Over: Preservation and Waiver on Appeal," at American Bar Association's Section of Litigation Annual Conference, presented by Thomas J. Donlon (4/2009)

      "The History of the Connecticut Supreme Court," at CBA Young Lawyers Section Appellate Committee Meeting at UConn Law School, co-presented by Jeffrey J. White and Wesley Horton, Esq., and Brendon Levesque, Esq. (11/24/2008)

      The History of the Connecticut Supreme Court, co-authored by Jeffrey J. White and Wesley W. Horton, coauthor of Chapters 6 and 7, which discusses the history of the Supreme Court from the 1860s through 1910 (2008)

      "A Few Do's and Don'ts of Oral Argument," published in ABA Appellate Practice Journal, authored by Thomas J. Donlon (Winter 2007)

      "Key Differences Between Appeals in the Second Circuit and Connecticut's Appellate Courts," at Connecticut Bar Institute Seminar, presented by Thomas J. Donlon (9/2007)

      "Winning Management of Legal Issues through Trial and Appeal," at American Bar Association Annual Meeting, co-presented by Thomas J. Donlon and Judge Michael Daley Hawkins, 9th Circuit, and Ms. Judith Miller, GC Bechtel Corp. (8/2007)

      Superseding and Staying Judgements: A National Compendium, authored by Linda L. Morkan, contributing chapter author (2007)

      "What Movies Teach Us About Appellate Advocacy," at American Bar Association annual meeting, presented by Thomas J. Donlon (8/2006)

      "Clarity Is an Absolute for Effective Advocacy," published in DRI For The Defense, authored by Linda L. Morkan (2006)

      "The Butler-Park Court," published in Connecticut Law Review, co-authored by Jeffrey J. White and Wesley W. Horton, Esq., about the Connecticut Supreme Court during the Civil War period (Winter 2005)

      "The Baldwin-Hamersley Court," published in Connecticut Bar Journal, co-authored by Jeffrey J. White and Wesley W. Horton, Esq., about the Connecticut Supreme Court from 1890 to 1910 (Fall 2005)

      "Beware of Euphemisms," published in DRI For The Defense, authored by Linda L. Morkan (1/2004)

      "First, Let's Sue All the Lawyers," published in Connecticut Law Tribune, authored by Linda L. Morkan (6/3/2002)

      "Hey, Judge Let Me Tell You Why I'm Right...," published in Connecticut Law Tribune, authored by Linda L. Morkan (4/1/2002)

      "Prepping for Showtime," published in Connecticut Law Tribune, authored by Linda L. Morkan (2/18/2002)

      "Sweet Success," published in Connecticut Law Tribune, authored by Linda L. Morkan (1/14/2002)

      "It's Hip to Help Jurists Stumble Your Way," published in Connecticut Law Tribune, authored by Linda L. Morkan (12/17/2001)

      "Hooked on Conference of Appellate Geeks," published in Connecticut Law Tribune, authored by Linda L. Morkan (11/12/2001)

      "Back to (Dirty) Work After Dirty Deed," published in Connecticut Law Tribune, authored by Linda L. Morkan (10/8/2001)

      "Rhetorically Speaking, the Issue Is Footnotes," published in Connecticut Law Tribune, authored by Linda L. Morkan (9/10/2001)

      "In Time (Sigh), Court May See the Light," published in Connecticut Law Tribune, authored by Linda L. Morkan (8/13/2001)

      "Understanding Appellate Work Is Kid Stuff," published in Connecticut Law Tribune, authored by Linda L. Morkan (7/16/2001)

      "Second Circuit Primer," at Stamford Bar Association , presented by Linda L. Morkan (5/2000)

      "Amendments to the Federal Rules of Appellate Procedure," at Connecticut Bar Association (CBA) , presented by Linda L. Morkan (9/1998)

      "Changes to the Appellate Rules of Procedure," published in Connecticut Lawyer at , authored by Linda L. Morkan (1/1997)

      "Preserving the Issues for Appeal," at CBA, presented by Linda L. Morkan (9/1995)

      "Connecticut Appellate Practice," at Lorman Education Service , presented by Linda L. Morkan (11/1994)

      "Annual Appellate Writing Seminar," at University of Connecticut Institute of Writing and University of Connecticut School of Law , presented by Linda L. Morkan (10/1994)

      "Effective Motion Practice in Connecticut," at Lorman Education Service, presented by Linda L. Morkan (1992, 1993, and 1994)
      • » more info

      "Transfer of Cases from the Appellate to Supreme Court: A Blow to Effective Advocacy?" published in Connecticut Lawyer, authored by Thomas J. Donlon (May/June 2010)

Our Team

Chair

Members